Resolution 1993-50
"-
-"
.
.
~.~
RESOLUTION NO. 93-50
RESOLUTION CALLING FOR CONSTRUCTION BIDS
NORTII FOREST STREET ASSESSMENT DISTRICT
The City Council of the City of Gilroy resolves:
1. This Council has given preliminary approval to the report of the Engineer
of Work for' improvements in North Forest Street Assessment District, City of Gilroy,
County of Santa Clara, State of California. The report includes plans and specifications
for the construction of improvements described in the report.
2. The City of Gilroy will receive sealed proposals for this construction not
later than 2:00 P.M. on September 23, 1993, in the Department of Purchasing located at
City Hall, 7351 Rosanna Street, Gilroy, California. At that time and place the sealed
proposals will be publicly opened, examined and declared.
3. The City reserves the power in its discretion to reject all proposals. The
award of construction contract, if made, shall be made to the lowest responsible bidder
within the time fixed in the specifications (or any extension of time agreed to by the
City and the lowest responsible bidder).
4. The City Clerk is directed to publish a notice inviting sealed proposals in
the Gilroy-Morgan Hill Dispatch in accordance with the Local Agency Public
Construction Act. The Engineer of Work is authorized to give additional notice and to
distribute additional information as necessary in the judgment of the Engineer of Work,
to secure competitive bidding.
5. The City Council hereby determines that in the event the contractor does
not complete the work within the time specified in the proposed contract or within such
further time as this Council shall have authorized, the contractor shall pay to the City
liquidated damages in the amount of $1,000 per day for each and every one day's delay
in finishing the work beyond the completion date specified in said contract. Additional
provisions with regard to said time of completion and liquidated damages are set forth
in the specifications, which provisions are hereby referred to and incorporated herein
by reference.
*
*
*
RESOLUTION NO. 93-50
ORIGINAL
,
.~
.
.
"'"
.
.
I HEREBY CERTIFY THAT the foregoing resolution was duly and regularly
adopted and passed by the City Council of the City of Gilroy, California, at a regular
meeting thereof held on the 16th day of August, 1993, by the following vote of the
members thereof:
AYES, and in favor, thereof, Councilmembers: GILROY, HALE, NELSON,
VALDEZ and GAGE.
NOES, Council members: None
ABSENT, Councilmembers: KLOECKER and ROWLISON.
AP;UJL1. .
M.y", Y
RESOLUTION NO. 93-50
4~~'~~i~
2